مثنى مها. كلية التربية للبنات

Abstract Despite the urgent need to service projects in most provinces, But they face manyproblems,The most important of them is the executiondelay at limited time, thus causing severalnegative effects for the project and participating parties The study showed there are four main parties whichcause the delay in the projects, and these are represented by The government's laws andregulations, Contractor, Karbala Municipality, and External conditions
Followed by a statistics, being carried out as frequently as each of delaying factors, Thetenmost frequent factors in the delay of Municipality projects were : Delayed arrival of thefinancial allocations, The bureaucracy and restrictive regulations, Additional statements andchange orders, Crossing of infrastructure services, Weakness of contractor's competence,Ineffective planning and scheduling, Shortage of labors in thework site, The procedures takenwhen the Contractor is delay such as Warning and drawing work, Public holidays and occasionsand closing of the roads, Encroachments

This leads to distrust betweenstakeholders,recourse to the courts, loss of money and delay tobenefitting from the services ofthose projects.

30
مها (اسم)
To achieve the objectives of this study, a Case Studymethod has been adopted in a sample of Karbala Municipality's projects to get the required dataand information, and used File — Maker programto facilitate the collection and organization ofdata
المقصور
So This study aims to identify The causing factors of delay in the service projects,and Shed light on the most important factors and putting the solutions to improve the Execution ofprojects with the least delays possible
الأردن المهيأ

.

مها (اسم)
الأردن المهيأ
الأردن المهيأ